Terms & Conditions
These terms accompany every GravelBoss proposal. They are referenced on your proposal PDF and form part of the agreement when you accept your quote.
Scope & Changes
Work is limited to the scope described on Page 2. Any changes require a written change order with agreed price adjustment before work begins.
Payment
Deposit is due upon signing. Balance is due on the day of completion before crew leaves the site. Late payments accrue interest at 1.5% per month.
Credit Card Surcharge
Credit and debit card payments are subject to a 3% processing surcharge. Cash and check payments have no surcharge.
Scheduling
Work will be scheduled within 2–4 weeks of deposit receipt. Exact date confirmed 48 hours in advance. Weather delays do not constitute breach of contract.
Warranty
90-day workmanship warranty from date of completion. Covers defects in grading, compaction, and material placement. Does not cover: normal wear and settling, snow plow damage, heavy vehicle damage (>10 tons), acts of nature, customer modifications, or failure to maintain drainage channels.
Existing Conditions
Contractor is not responsible for underground utilities, septic systems, irrigation lines, or hidden conditions below the gravel surface. Customer is responsible for calling 811 to mark utilities before work begins.
Liability
Contractor carries general liability insurance. Total liability is limited to the contract value. Contractor is not liable for pre-existing damage, landscaping damage from necessary equipment access, or conditions outside the work area.
Force Majeure
Neither party is liable for delays caused by weather, natural disaster, pandemic, supply chain disruption, or government action.
Cancellation
Customer may cancel within 3 business days of signing for a full refund of any deposit paid. After 3 business days, the deposit is non-refundable. Contractor may cancel with full deposit refund if site conditions make work unsafe or impractical.
Dispute Resolution
Disputes shall be resolved first by direct negotiation (30-day window). If unresolved, binding arbitration under AAA Construction Industry Arbitration Rules. For claims under $10,000, a single arbitrator on documents only. Each party bears its own costs. Either party may pursue claims in small claims court.
Lien Waiver
Contractor provides a full lien waiver upon receipt of final payment.
Indemnification
Each party indemnifies the other against claims arising from their own negligence or willful misconduct.
Questions
Questions about these terms can be sent to info@gravelboss.co or handled by phone at (440) 644-4004.